1. Definitions
In these T&Cs:
“Premo Projects,” “we,” “us,” or “our” refers to Premo Projects, the service provider.
“Client,” “you,” or “your” refers to the person or entity engaging with Premo Projects for services.
“Services” refers to any carpentry, construction management, design approvals, or turnkey shed kit solutions provided by Premo Projects.
“Agreement” refers to the contract formed when you accept a quote or engage us for services.

2. Scope of Services
Premo Projects agrees to provide services as outlined in the quote or agreement provided to you. Any additional work or changes requested may require a variation to the original agreement, subject to additional fees.

3. Quotes and Pricing
All quotes provided are valid for 30 days from the date of issue unless otherwise specified.
Prices are subject to change if the scope of work changes or if delays occur outside our control.
All pricing includes GST (Goods and Services Tax) unless otherwise stated.

4. Payment Terms
A deposit of 50-75% of the total project cost is required to secure our services, as specified in the quote.
Progress payments may be required based on milestones agreed upon in the project schedule.
Final payment is due upon completion of the project or delivery of the shed kit.
Payments must be made by bank transfer, credit card, or any other agreed payment method.
Late payments may incur interest at the rate of 10% per annum, calculated daily, plus recovery costs.

5. Variations and Additional Costs
If changes to the original scope are requested, a written variation agreement will be provided, and additional costs may apply.
If delays occur due to factors beyond our control (e.g., weather conditions, council delays, or material shortages), additional charges may apply for idle time, labour, or rescheduling.

6. Cancellations and Refunds
Cancellations must be made in writing.
If the client cancels before the project commences, Premo Projects may retain part of the deposit to cover administrative costs.
If the project has commenced, the client will be liable for the cost of materials, labour, and any other expenses incurred up to the date of cancellation.
Refunds will only be issued in accordance with NSW Fair Trading regulations.

7. Warranties and Guarantees
Premo Projects provides a workmanship guarantee in compliance with NSW Fair Trading regulations.
Any defects caused by materials or workmanship will be rectified within 12 months from project completion, provided the client notifies us in writing within a reasonable time.
The warranty does not cover wear and tear, misuse, or changes made by third parties.

8. Limitation of Liability
Premo Projects will take all reasonable care and skill in performing the services. However, we are not liable for:
Any indirect, incidental, or consequential loss arising from delays or changes.
Losses or damages resulting from information provided by the client that is incomplete, inaccurate, or delayed.
Our liability is limited to the cost of the service provided or as required under NSW law.

9. Intellectual Property
Any designs, plans, or concepts created by Premo Projects remain our intellectual property unless agreed otherwise.
The client is granted a non-exclusive licence to use any designs or plans provided for the intended project only.

10. Site Access and Client Responsibilities
The client must ensure safe access to the site for Premo Projects personnel, subcontractors, and suppliers.
The client must provide accurate project information and any necessary approvals prior to project commencement.
Premo Projects reserves the right to suspend work if access is restricted or conditions are unsafe.

11. Force Majeure
Premo Projects is not liable for any failure or delay in performance due to circumstances beyond our control, including but not limited to:
Natural disasters (e.g., floods, storms)
Strikes, lockouts, or industrial action
Supplier delays or material shortages
Government restrictions or council delays

12. Dispute Resolution
In the event of a dispute, both parties agree to attempt mediation through NSW Fair Trading before pursuing further legal action.
If mediation is unsuccessful, either party may pursue the matter through the relevant tribunal or court.

13. Privacy and Confidentiality
Premo Projects will handle all personal information in accordance with our Privacy Policy and applicable Australian privacy laws. We will not disclose your information to third parties without your consent, except as required by law.

14. Termination of Agreement
Either party may terminate the agreement by providing written notice.
Premo Projects reserves the right to terminate the agreement if the client:
Fails to make payments as agreed.
Provides false or misleading information.
Breaches any material term of this agreement.
In the event of termination, the client will be liable for all costs incurred up to the date of termination.

15. Compliance with NSW Law
Premo Projects complies with NSW Fair Trading regulations and all other applicable building and safety codes.
It is the client’s responsibility to ensure any specific council requirements are met before the project commences, unless Premo Projects is contracted to manage design approvals.

16. Governing Law
These T&Cs are governed by the laws of New South Wales, Australia. Any disputes arising from this agreement will be subject to the jurisdiction of NSW courts and tribunals.

17. Changes to Terms and Conditions
Premo Projects reserves the right to update or modify these T&Cs at any time. Any changes will be posted on our website, and the updated terms will apply to all new agreements entered into after the changes take effect.

18. Contact Information
If you have any questions or concerns about these T&Cs, please contact us:
Premo Projects
Phone: 0480 290 883